341_2013-03-29-13-44-18_1364544858

7/30/2019 341_2013-03-29-13-44-18_1364544858

1/109

1

DELHI JAL BOARD

OFFICE OF THE EXECUTIVE ENGINEER WEST III Contact No. 25471004

NANGLOI PH-III: NEAR BARAT GHAR: NEW DELHI-41. Sh. ANAND PAL E.E

!#!#%###!

&% ()()(+,#)./

&!#.0 12

#

2

()()(+,#,((./

3 ()()(+,,(./3

4 1

5S.

No.

Description Amount put to

Tender

E/Money Completion

Period

1. Improvement of water supply / removal of contamination by

replacing damaged portion of water line in Parampuri and

adjoining area in AC-32 West-III.Rs.8,94,299/- Rs.18,000/- 60 days

2. Improvement of sewerage system by desilting of sewer line inSubash Park Extn B Block on Raja Puri Road in AC 32.

West-III.Rs.5,56,240/- Rs.6,000/- 60 days

6! 7( ! 2 %33#1!3!

## # !# ! ! 3 ! ##51+7, #

5%#4#

3 5 ! 3

0

3(+,3

EXECUTIVE ENGINEER (WEST) IIICopy to:-

1. Secy to CEO/Mem.(A)/Mem.(F) /Mem.(WS) /Mem.(Dr)/ CVO. For kind information.

2. C.E. (WEST) 3. Dir. (F&A) /S.E (WEST) 4. AO (WEST) 5.AAO (WEST)

6. Notice Board, 7. D/M-I to put up the justification /ZE/JE 8. PRO Cell. Jhandawalan.

9.Contractors Association,36, Block-BA, Paschim Shalimar Bagh New Delhi-110088

10.SYNDICATE BANK, 43, RANI JHANSI ROAD, NEW DELHI-110055. PH-23528976.

EXECUTIVE ENGINEER (WEST) III

enders for Road Improvement by Delhi Jal Board-1745034125
http://tenders.indiamart.com/

7/30/2019 341_2013-03-29-13-44-18_1364544858

2/109

2

ADDITIONAL INFORMATION OF NIT

Subject: Special information regarding eligibility criteria and other requirement for the work listed in NIT

No.67- (2012-13), of EE (WEST) III .

The tenderer must be fully conversant with the documents to form part of contract agreement i.e. Instructions to

bidders, General Conditions , Specification, Clauses of Contract, Safety Codes, Model Rules, CPWD contractor

labour regulations (Standard documents) are available on web site. However these are not to be attached with

tender documents. Section-3 of Building and other construction worker welfare Cess act 1996 shall be

applicable.However the eveled versions of these documents as attached/uploaded with NIT shall be used &shall form part of contract agreement.

The tenderer shall submit the offer under two bid system i.e. Bid part-A (Technical) & Bid Part-B (Financial)

through Online Submission of tender .

1. Bid part-A should contain scanned documents giving details of Earnest Money and Eligibility Criteria. ! ##%# & &

##(!)%##+,,.#(#.#,

/01.21345#+ #4!4.2.2#466#/+#4%78% #4 &% 6 6, ## ,

&9#,#4#5##)88###.2&/##78/6

):;0),=1#4>=>,=5>

1 ) =)>

8##8%&.28%###4/

#

7/30/2019 341_2013-03-29-13-44-18_1364544858

3/109

3

B). the contractor who neither executes the C.A within stipulated period as stated in work order nor takes up the

execution of work even after lapse of date of start of work.

C).

8!#!

Tender shall be valid for mentioned in Nit form the date of receipt of Bid. The DJB reserves the right to reject

any or all tenders without assigning any reason.

EXECUTIVE ENGINEER (WEST) III

http://tenders.indiamart.com/http://tenders.indiamart.com/

7/30/2019 341_2013-03-29-13-44-18_1364544858

4/109

4

UNDERTAKING

(1) Format for the undertaking to be submitted by bidder that they have not been debarred / blacklisted as on

date in any department:-

IT IS HEREBY CERTIFED THAT I/WE HAVE NOT BEEN DEBARRED/BLACKLISTED FOR

PARTICIPATING IN TENDERING PROCESS BY ANY OF THE DEPARTMENT AS

ON.

SIGNATURE


7/30/2019 341_2013-03-29-13-44-18_1364544858

5/109

5

1.

Name of work: Improvement of water supply / removal of contamination by replacing damaged portion of water line in

Parampuri and adjoining area in AC-32 West-III.

S.No Description of Item Qty. Rate Unit Amount

1 Demolishing cement concrete manually/ by mechanical meansincluding disposal of material within 50 metres lead as perdirection of Engineer - in - charge. Nominal concrete 1:3:6 or

richer mix (i/c equivalent design mix)

49.80 671.05 Cum 33418.29

2 Cutting of bituminous road and taking out soling metalling I /C sorting screening and stacking within 50m lead and cost of

barricading and chowkidar.

74.70 390.4 Cum 29162.88

3 Demolishing dry brick pitching in floors, drains etc. includingstacking serviceable material and disposal of unserviceablematerial within 50 metres lead.

24.90 363.35 Cum 9047.42

4 Demolishing R.C.C. work manually/ by mechanical meansincluding stacking of steel bars and disposal of unserviceablematerial within 50 metres lead as per direction of Engineer - in-

charge.

1.00 978.95 cum 978.95

5 Excavation trenches of required width for pipes, cables etc. i/cexcavation for sockets and dressing of sides, ramming of

bottoms, depth up to 1.50m i/c getting out the excavated soil,and then returning the soil as required in layers not exceeding

20 cm in depth i/c consolidating each deposited layer by

ramming, watering etc. and disposing of surplus excavated soilas directed within a lead of 50 m. exceeding 80 mm dia but not

exceeding 300mmdia. a) All kind of soil.

360.00 165.6 Mtr 59616.00

6 Providing and laying S&S centrifugally cast (spun) ducile ironPipes Conforming to IS 8329 Class K-7:100 mm dia. Pipe

250.00 840.25 M 210062.50

7 150 mm dia. Pipe 50.00 1229.05 M 61452.50

8 Providing and laying D.I standard specials of class K/12Suitable a) push on joints as per IS 9523 upto 600 mm dia.

1.25 13958.95 Qtls 17448.69

9 b) Mechanical joints upto 600 mm dia 0.49 14760.35 Qtls 7232.5710 Providing and laying S&S C.I. standard specials such as tees,

bends, collars, tapers, caps etc. (Heavy class) upto 300mm dia0.15 4202.35 Qtls 630.35

11 Providing/Fixing C.I S/V (with cap) complete with bolts, nuts,rubber insertion etc. (The tail piece if required will be paid

separately) Class I

100 mm dia.

1.00 3068.35 Each 3068.35

12 150 mm dia 1.00 4487.75 Each 4487.75

13 Labour for cutting C.I. Pipe with Steel Saw.100 mm dia

13.00 55.65 Each 723.45

14 150 mm dia 7.00 104.7 Each 732.90

15 Hire charges of pump set (Actual Pumping will be paid) cap.@4000 L/Hrs.

50.00 580.75 P.Day 29037.50

16 Providing push on joints to centrifugally ( spun ) cast iron

pipes or Ductile iron pipes i/c testing of joints and i/c the costof rubber gasket.100 mm dia.

45.00 49.25 Each 2216.25

17 150 mm dia 9.00 79.05 Each 711.45

18 Providing C.I.D. Joints to A.C. pressure pipes and plain endedC.I. Specials with collars, rubber rings flanges, bolts, and nutscomplete including testing of joints.100 mm dia

13.00 194 Each 2522.00

19 150 mm dia 7.00 282.85 Each 1979.95

20 repairing & shifting the existing house water connection i/c G.Ifitting such as elbow nipples, sockets,unions etc & complete inall respects

10.00 398 each 3980.00

21 Shifting of water connection from old C.I. water line to newC.I. water main i/c boring with C.I. water main i/c P/F brassferrule 6mm dia (wt. Not less than 150 gms. ) and i/c 1.00 mtr.

Long G.I. pipe 15mm dia nominal bore i/c fitting, trenching,refilling and disconnecting the existing connection from oldwater main i/c plugging the bore hole and depositing all

serviceable as well as unserviceable material obtained during

82.00 421.9 Each 34595.80


7/30/2019 341_2013-03-29-13-44-18_1364544858

6/109

6

disconnection in the store complete in all respects as directedby Engineer-In-Charge.(cost of road restoration shall be paidseparately as per site condition)

22 Providing & fixing G.I. Union in G.I Pipe i/c cutting andthreading the pipe and making long screw etc. complete (newwork).15mm dia

82.00 119.6 Each 9807.20

23 Providing & fixing G.I. Pipe complete with G.I. fittings i/c

trenching and refilling etc. (external work)15mm dia

123.00 142.25 Mtr. 17496.75

24 Providing, laying and jointing glazed S.W. Pipe grade Awith stiff mixture of cement mortar in the proportion of 1:3 (1

cement : 3 fine sand) i/c testing of joint etc. complete.150mmdia

45.00 219.05 M 9857.25

25 P/L cement concrete 1:5:10 (1 cement: 5 C.S: 10 graded stoneagg. 40mm nominal size) upto haunches of S.W. pipes i/c bedconcrete as per std. design.150mm dia S.W. Pipe

45.00 382.75 M 17223.75

26 Earth work in excavation by mechanical means(hydraulicexcavator)/manual means over areas (exceeding 30 cm indepth 1.5 mtr. in width as well as 10 sqm. on plan) i/c disposalof excavated earth lead upto 50 mtr. disposed earth to be

leveled and neatly dressed.a) All kind of soil.

29.70 129.35 Cum 3841.70

27 b) Extra for every additional lift of 1.5 or part thereof in allkind of soil 5.00 34.6 Cum 173.00

28 Filling available excavated earth (excluding rock) in trenchesplinths sides of foundation etc. in layer not exceeding 20 cm indepth. Consolidating each deposited layer by ramming andwatering lead upto 50 mtr. lift upto 1.5 mtr.

29.70 83.8 Cum 2488.86

29 Providing and fixing 1.6 m high corrugated GI sheetbarricading supported on safeda ballies 100 mm dia two meterhigh place at 2.5m centre to centre CGIsheet fixed with nails of

required length and dia to safeda ballies i/c excavating holes ofsize 30 X 30 X 40 cm. getting out of the excavated soil andthen returning soil including consolidating by ramming andwatering etc. all complete i/c disposal of surplus excavated

earth with in a lead of 50 m and lift up to 1.5 m and paintingon full surface of C.G.I. sheet on one side with bright paint of

red and white Colour in vertical strips 0.3 mtr widealternatively as directed by Engineer In Charge.

312.00 25.55 Sqm 7971.60

30 Carriage of surplus earth/malba by mechanical transport i/cloading and unloading and stacking upto 5km lead (actual lead

will be paid)

50.00 100.74 Cum 5037.00

31 Providing and laying 75 mm thick compacted bed of dry brickaggregate of 40 mm thick nominal size including spreading,

well ramming, consolidating and grouting with jamuna sand,including finishing smooth etc. complete as per direction ofEngineer-in-charge

249.00 97.55 Sqm 24289.95

32 Providing and laying in position ready mixed plain cementconcrete, with cement content as per approved design mix andmanufactured in fully automatic batching plant and transported

to site of work in transit mixer for all leads, having continuousagitated mixer, manufactured as per mix design of specified

grade for plain cement concrete work, including pumping ofR.M.C. from transit mixer to site of laying and curing,

excluding the cost of centering, shuttering and finishing,including cost of curing, admixtures in recommendedproportions as per IS :9103 to accelerate/ retard setting of

concrete, improve workability without impairing strength and

durability as per direction of the Engineer - in - charge. M-15grade plain cement concrete (cement content considered@ 240

kg/cum)

48.15 5086.95 Cum 244936.64

33 Brick work with common burnt clay F.P.S. (non modular)bricks of class designation 7.5 in foundation and plinth in:

cement mortar 1:4

4.14 3508.25 Cum 14524.16

34 12 mm cement plaster 1:3 (1 cement: 3 C sand) finished with afloating coat of neat cement.

36.00 164.5 Sqm 5922.00

35 Providing leak proof rockas in 150mm dia to 300mm diarunning sewer line with earth filled in empty (PVC) cementbags including removal of the same after completion of work.

18.00 350.2 Each 6303.60

36 Construction of bund with filled up earth in empty(PVC) 50.00 8.25 Nos. 412.50


7/30/2019 341_2013-03-29-13-44-18_1364544858

7/109

7

cement bags (excluding the cost of earth which will beavailable at the site of work ) including stitching, stacking andplacing in position and removing the same etc. complete and

including the cost of empty PVC cement bags complete.

37 Reinforced cement concrete work in beams, suspended floors,roofs having slope up to 15 landings, balconies, shelves,

chajjas, lintels, bands, plain window sills, staircases and spiral

stair cases up to floor five level, excluding the cost ofcentering, shuttering, finishing and reinforcement, with 1:2:4 (1cement : 2 coarse sand : 4 graded stone aggregate 20 mm

nominal size).

1.00 5494.55 Cum 5494.55

38 Steel reinforcement for R.C.C. work including straightening,cutting, bending, placing in position and binding all completeupto plinth level

50.00 62.25 Kg 3112.50

39 Supply & stacking at site precast concrete manhole cover withsteel fibre of ISI mark confirming to IS:12592 part1 of EHD-35with matching frame of class EHD-35 IS:12592 part2 with875mm external dia & clear 560mm internal dia.

2.00 1150 each 2300.00

40 894298.56


7/30/2019 341_2013-03-29-13-44-18_1364544858

8/109

8

2.Name of work: Improvement of sewerage system by desilting of sewer line in Subash Park Extn B Block on Raja Puri

Road in AC 32. West-III.

S.No Description of Item Qty. Rate Unit Amount

1 Providing and fixing 2.0 m high corrugated G.I. sheetbarricading with safeda ballies of 100 mm dia 2.8 meter long

post 30cm girth(min.) for CGI sheet and every 12th post to bestrutted with ballies and fixing with nails etc. includingexcavation holes of size 0.30x0.30x 0.80 meters getting out theexcavated soil and then returning the soil includingconsolidating by ramming watering etc. disposal of surplus

earth as directed within a lead of 50m and lift 1.5 m and

painting with bright red and white paint vertical strips 0.30mwide and 1.25 m apart center to center as per drawing and as

directed by engineer-in-charge.

300.00 31.80 M 9540.00

2 Cutting of bituminous road and taking out soling, metallingincluding sorting, screening and stacking and cost ofbarricading and chowkidar with in a lead of 50 mtrs.

24.00 390.40 Cum 9369.60

3 Demolishing cement concrete and disposal of material with in50 meter lead: 1:3:6 or richer mix. 24.00 671.05 Cum 16105.20

4 Demolishing brick work manually/mechanical means includingstacking of serviceable material and disposal of unserviceablematerial with in 50 meter lead: In cement mortar.

6.27 566.60 Cum 3552.58

5 Earth work in excavation by mechanical/ manual means overareas (exceeding 30cm in depth. 1.5m in width as well as 10sqm on plan) including disposal of excavated earth, lead upto50m and lift upto 1.5m; disposed earth to be levelled and neatlydressed All kinds of soil

69.10 129.35 M3 8938.09

6 Extra for every additional lift or part thereof in: All kinds ofsoil.

2.00 34.60 Cum 69.20

7 Brick work with common brunt clay F.P.S (non modular)bricks of class designation 75 in foundation and plinth in

cement mortar 1:4 ( 1 C : 4 C sand )

10.45 3508.25 M3 36661.21

8 12mm cement plaster of mix 1:4 (1 cement : 4 coarse sand) 90.89 132.10 M2 12006.57

9 Neat cement punning 34.61 31.10 M2 1076.37

10 Providing at site ISI Marked PE-80, PN-4 & SDR-19 HDPEpipe as per IS:14333 suitable for butt fusion jointing: Outer

Diameter/innar Diameter 280 mm/250mm

5.00 1381.00 M 6905.00

11 Laying and positioning in trenches PE-80, PN-4 pipes as perIS:7634(Part-II& III) including testing but excluding the costof jointing. Outer Diameter/innar Diameter 280 mm/250mm

5.00 12.20 M 61.00

12 Providing butt fusion welding joint to PE-80, PN-4 HDPE pipeas per DVS:220 Part-II Outer Diameter/inner Diameter 280mm/250mm

1.00 117.10 M 117.10

13 15mm cement plaster on rough side of single or half brick wallof mix : 1:4 (1 C : 4 CS)

5.00 153.65 Sqm 768.25

14Constructing brick masonry circular manhole 3'0" or 0.91 minternal dia. at the bottom and 1'10" (0.56) at the top, depthupto I.L. 3'0" or 0.91 m built in brick work with extruded burnt

sewer bricks conforming to IS-4885-1988 in curved on plan incement mortar 1:4 (1 cement : 4 coarse sand ) excludingexcavation and soling but including 9" or 0.23 m thickfoundation cement concrete 1:3:6 ( 1 cement: 3 coarse sand : 6

graded stone aggregate 40 mm nominal size ) includingcentering and shuttering and fixing S.F.R.C. manhole cover &

frame(heavy duty) 560 mm dia internal fixed in cementconcrete 1:2:4 (1 cement :2 c.sand :4 stone aggregate 20 mmnominal size ) and 12 mm thick cement plaster on both inside

and outside with cement mortar 1:4 ( 1 cement :4 coarse sand)and inside plaster to be finished with a floating coat of neatcement, making necessary channels in cement concrete 1:2:4 (1

cement : 2 coarse sand : 4 graded stone aggregate 20 mmnominal size) all complete as per departmental drawing and as

directed by Engineer-In-Charge.Note: cost of manhole coverand frame shall be paid separately.

1.00 6027.40 Each 6027.40


7/30/2019 341_2013-03-29-13-44-18_1364544858

9/109

9

15 Extra per m depth of 3'0" or 0.91m internal circular manholebeyond 3'0" or 0.91m and upto5'-6" or 1.67m depth built inbrickwork with with extruded burnt sewer bricks conforming to

IS-4885-1988 in curved in cement mortar 1:4 (1 cement:4c.sand ) 12 mm thick cement plaster both inside and outsidewith cement mortar 1:4 (1cement :4 coarse sand)and insideplaster to be finished with a floating coat of neat cement , all

complete as per departmental drawing and as directed byEngineer-In-Charge.Note; Cost of providing and fixing plasticencapsulated footrest shall be paid separately

0.20 4354.35 M 870.87

16 Providing orange colour safety foot rest of minimum 6mmthick plastic encapsulated as per IS:10910 on 12 mm dia steelbar conforming to IS 1786 having minimum cross section as

23mm x 25 mm and over all minimum length 263mm and

width as 165 mm with minimum 112 mm space betweenprotruded legs having 2 mm tread on top surface by ribbing or

chequering besides necessary and adequate anchoringprojections on tail length on 138mm as per standard drawing

and suitable to with stand the bend test and chemical resistancetest as per specifications and having manufacturer's permanentidentification mark to be visible even after fixing ,including

fixing in manhole with 30x20x10cm cement concrete block

1:3:6( 1 cement: 3coarse sand : 6 graded stone aggregate 20mmnominal size) as per design.

10.00 258.70 Each 2587.00

17 Supply and stacking at site precast concrete manhole coverwith steel fibre of ISI mark conforming to IS.12592 part I of

EHD35 with matching frame of class EHD - 35 IS 12592 part

II with 875 mm external dia and clear 560mm internal dia. e/cfixing each manhole cover shall be engraved with following

permanent making specified in LS code. year of manufacturing

B) Delhi Jal Board Sewer.d) Extra Heavy Duty/ Heavy Duty.All K.K. Brand Frame & Cover or equivalent make.1.Heavyduty (HD-20 )

10.00 1030.00 Each 10300.00

18 Extra Heavy Duty (EHD-35) 21.00 1150.00 Each 24150.00

19 Fixing of manhole cover and frame. 30.00 36.60 Each 1098.00

20Providing & laying in position cement concrete of specified

grade e/c the cost of centering and shuttering all work up-toplinth level. 1:2:4 (1 Cement : 2 coarse sand : 4 graded stoneaggregate 20 mm nominal size

15.30 4514.05 M3 69064.97

21 1:5:10 (1 cement: 5 coarse sand : 10 graded stone aggregate 40mm nominal size

9.55 3357.40 M3 32063.17

22 Desilting of sewer line based on bucket system in running andunder foul condition for depth not exceeding 1.5m i/c removal

of stone,brick bats, garbage,silt etc .and stacking the same onthe bank of sewer line manhole at a distance upto 50m from

center of sewer line as per CPWD specification complete and

lift upto 1.5m.

99.71 340.00 Cum 33901.40

23 Desilting and taking out silt/debris/ rubbish etc.from Main/Peripherial sewer which is partially surcharged with the help

of sewer cleaning machine including all cost of labour material,

T&P, watch & ward,caution boards,diesel,mobile oil, greaseetc.and wear & tear of machine all complete. The silt / debrisshall be carted to municipal dumping ground or as directed by

Engineer-in Charge. Any damage to any M/Hole shall berectified on his own cost.

87.79 1817.10 cum 159523.21

24 Pumping out water by providing pump sets of 4000 litres perhours for a working shift of 8 hours per day i/c the cost ofpump labour & fuel and watch & ward etc. complete asdirected by Engineer in- Charge.

100.00 580.75 Each 58075.00

25 Providing leak proof rockas in 150mm dia to 300mm diarunning sewer line with earth filled in empty (PVC) cementbags including removal of the same after completion of work.

20.00 350.20 Each 7004.00

26 Repairing /shifting of the existing house water connectionincluding G.I. fittings such as elbows, nipples , sockets, unions,

ferrules, etc. complete.

10.00 398.00 Nos. 3980.00

27 Filling available excavated earth (excluding rock) in trenchesplinth sides of foundation etc. in layers not exceeding 20cm.in

depth consolidating each deposited layer by ramming and

69.10 83.80 Cum 5790.58

http://tenders.indiamart.com/http://tenders.indiamart.com/

7/30/2019 341_2013-03-29-13-44-18_1364544858

10/109

10

watering lead up to 50mtr. Lift up to 1.5 mtr.( 2.26/12).

28 Carriage of material by mechanical transport i/c loadingunloading and stacking up to 5 km lead earth

2.00 125.92 Cum 251.84

29 Manure or sludge 91.74 109.50 Cum 10045.53

30 Building rubbish, 54.27 100.74 Cum 5467.16

31 Construction of bund with filled up earth in empty(PVC)

cement bags (excluding the cost of earth which will beavailable at the site of work ) including stitching, stacking andplacing in position and removing the same etc. complete andincluding the cost of empty PVC cement bags complete.

10.00 8.25 Nos. 82.50

32 Providing ,laying and jointing glazed stoneware pipes grade 'A'with stiff mixture of cement mortar in proportions 1:1 (1cement : 1 fine sand) including testing of joints etc.Complete.100mm dia

20.00 150.10 M 3002.00

33 150mm dia 20.00 219.05 M 4381.00

34 Providing and laying cement concrete1:5:10( 1cement :5coarse sand :10 graded stone aggregate40mm nominal size)

upto haunches of S.W. pipes including bed concrete as perstandard design: 100mm diameter of S.W. pipes

20.00 236.15 M 4723.00

35 150mm diameter of S.W. pipes 20.00 382.75 M 7655.00

36 Supplying & Filling in plinth with Jamuna sand under floorsincluding watering, ramming consolidating & dressingcomplete.

1.37 749.30 cum 1026.54

37 556240.34


7/30/2019 341_2013-03-29-13-44-18_1364544858

11/109

11

PROFORMA OF SCHEDULESSCHEDULE A

Schedule of quantities ---- Yes, Bill of quantities Attached

SCHEDULE BSchedule of materials to be issued to the contractor--- Nil

SCHEDULE CTools and plants to be hired to the contractor--- Nil

SCHEDULE DExtra schedule for specific requirements/ document for the work, if any--- NOT USED

SCHEDULE ESchedule of component of Cement, Steel, other Material, and Labour etc. for price escalation--- Not applicable

SCHEDULE FReference to General Condition of contract

Name of work: mentioned in Nit.

OPTION I (D.I) Amt Put to Tender : Rs. Mentioned in Nit

OPTION II (C.I) Amt put to tender : Rs. Mentioned in Nit

Item Rate : Rs. Mentioned in Nit

(i) Earnest money : Rs. Mentioned in Nit

(ii) Performance Guarantee : 5% of tendered value

(iii) Security Deposit : 5% of tendered value

GENERAL RULES & DIRECTIONS : Officer inviting tender

Definitions:Engineer-in-charge : E E (West) IIIGovernment / Govt of India : Delhi Jal Board

Accepting Authority : Delhi Jal Board

Percentage on cost of materials and

Labour to cover all Overheads and profits : 15%Standard Schedule of Rates : DSR-2012& MARKET RATES

Department : Delhi Jal Board

Clause 1 i) Time allowed for submission of performanceguarantee from the date of issue of letter of acceptance 10 Days

ii) Maximum allowable extension beyond the periodProvided in (i) above 03 Days

Clause 2.0 Authority for fixing compensation under clause 2.0 Superintending Engineer in Charge

Clause 2A Whether clause 2A shall applicable Not applicable

Clause 3A Whether clause 3A shall applicable Applicable

Clause 5 The time allowed for execution of the work Mentioned in Nit


7/30/2019 341_2013-03-29-13-44-18_1364544858

12/109

7/30/2019 341_2013-03-29-13-44-18_1364544858

13/109

13

Clause 12.2

& 12.3

Deviation limit beyond which clause 12.2 & 12.3

shall apply for building work30% of agreement quantity

Clause 12.5 Deviation limit beyond which clause 12.2 & 12.3 shall apply forfoundation work

100% of agreement quantity

Clause 16 Competent authority for deciding reduced rates S E concerned

Clause 25 Settlement of disputes and Arbitration Not Applicable

Clause36(i) For works with amount put to tender- above 10 lakhs: At least Graduate civilengineer is required

For works with amount put to tender- less than & up to 10 lakhs: At least Diploma civil engineer is

required

For minimum qualification,experience & rate of recovery may please refer to following table:

Rate at which recovery shall be made fromthe Contractor in the event of not fulfillingprovision of clause 36(i).

S.No

.

MinimumQualifications andexperience

required forPrincipal TechnicalRepresentative

Discipline

Designation(PrincipalTechnical/

TechnicalRepresentative)

Minimum

experienceNumber

Figure Words

1 Graduate Engineer Civil ProjectManager/Engineer

As persatisfaction ofEngineer-in-

Charge)

One Rs.20,000/- permonth

Rs. Twenty thousandper month

2 Diploma engineer Civil Technicalrepresentative

As persatisfaction ofEngineer-in-Charge)

One Rs 10000/- permonth

Rs Ten thousand permonth

Assistant Engineers retired from Government services that are holding Diploma will be treated at par with Graduate Engineers.

CLAUSE 42

(i)(a) Schedule/statement for determining theoretical quantity ofcement- on the basis ofDelhi Schedule of

Rates DSR 2012 printed by C.P.W.D.(ii) PERMISSIBLE VARIATION FOR DETERMINING THEORETICAL QUANTITY OF

CEMENT/STEEL:-

a) For works with amount put to tender not more than 5 lacs:Cement : 3% Plus/MinusSteel : 2% Plus/Minus

b) For works with amount put to tender more than 5 lacs.Cement : 2% Plus/Minus

Steel reinforcement & Structural Steel: 2% Plus/Minus

EXECUTIVE ENGINEER (WEST)III


7/30/2019 341_2013-03-29-13-44-18_1364544858

14/109

14

INSTRUCTION TO BIDDERS

1. Definitions

The Contract means the documents forming the tender and acceptance thereof and the formal

agreement executed between the competent authority on behalf of the Delhi Jal Board and theContractor, together with the documents referred to therein including these conditions, thespecifications, designs, drawings and instructions issued form time to time by the Engineer-in-

Charge and all these documents taken together, shall be deemed to form one contract and shall

be complementary to one another.

2. In the contract, the following expressions shall, unless the context otherwise requires, have themeanings, hereby respectively assigned to them :-

i) The expression works or work shall, unless there be something either in the subject or contextrepugnant to such construction, be construed and taken to mean the works by or by virtue of

the contract contracted to be executed whether temporary or permanent, and whether original,

altered, substituted or additional.

ii) The site shall mean the land / or other places on, into or through which work is to be executedunder the contract or any adjacent land, path or street through which work is to be executed under

the contractor any adjacent land, path or street which may be allotted or used for the purpose of

carrying out the contract.iii)The contractor shall mean the individual, firm or company, whether incorporated or not,

undertaking the works and shall include the legal personal representative of such individual or

the persons composing such firm or company, or the successors of such firm or company and the

permitted assignees of such individual, firm or company.

iv)The D.J.B. means the Delhi Jal Boardand its successors.v) The Engineer-in-charge means the Engineer Officer who shall supervise and be in charge of the

work and who shall sign the contract on behalf of the Delhi Jal Boardas mentioned in Schedule

'F' hereunder.vi)Government or Government of N.C.T. of Delhi shall mean the Delhi Jal Board.vii)Accepting Authority shall mean the authority mentioned in Schedule 'F'.viii) Excepted Risk are risks due to riots (other than those on account of contractor's

employees), war (whether declared or not) invasion, act of foreign enemies, hostilities , civil war,

rebellion revolution, insurrection, military or usurped power, any acts of Government, damages

from aircraft, acts of God, such as earthquake, lightening and unprecedented floods, and other

causes over which the contractor has no control and accepted as such by the Accepting

Authority or causes solely due to use or occupation by Government of the part of the works in

respect of which a certificate of completion has been issued or a cause solely due to

Government's faulty design of works.ix)Market Rate shall be the rate as decided by the Engineer-in-Charge on the basis of the cost of

materials and labour at the site where the work is to be executed plus the percentage mentioned

in Schedule "F" to cover, all overheads and profits.

x) Schedule(s) referred to in these conditions shall mean the relevant schedule(s) annexed to thetender papers or the standard Schedule of Rates of the Government mentioned in Schedule "F"hereunder, with the amendments thereto issued upto the date of receipt of the tender.

xi)Department means D.J.B. Government of N.C.T. of Delhi which invites tenders on behalf of theDelhi Jal Boardas specified in Schedule "F".

xii)Tendered value means the value of the entire work as stipulated in the letter of award.3. Scope and performance Where the context so requires, words imparting the singular only

also include the plural and vice versa. Any reference to masculine gender shall whenever required includefeminine gender and vice versa.


7/30/2019 341_2013-03-29-13-44-18_1364544858

15/109

15

4. The contractor shall be furnished, free of cost one certified copy of the contract documents except

standard specifications, Schedule of Rates and such other printed and published documents,

together with all drawings as may be forming part of the tender papers. None of these documentsshall be used for any purpose other than that of this contract.

5. Works to be carried outThe work to be carried out under the contract shall, except as otherwise provided in these

conditions, include all labour, materials, tools, plants, equipment and transport which may be

required in preparation of and for and in the full and entire execution and completion of theworks. The descriptions given in the Schedule of Quantities (Schedule-A) shall, unless otherwise

stated, be held to include wastage on materials, carriage and cartage, carrying and return of

empties, hoisting, setting, fitting and fixing in position and all other labours necessary in and for

the full and entire execution and completion of the work as aforesaid in accordance with good

practice and recognized principles.

6. Sufficiency of tenderThe Contractor shall be deemed to have satisfied himself before tendering as to the correctness

and sufficiency of his tender for the works and of the rates and prices quoted in the Schedule ofQuantities, which rates and prices shall, except as otherwise provided, cover all his obligationsunder the contract and all matters and things necessary for the proper completion and maintenance ofthe works.

7. Discrepancies and Adjustment of ErrorsThe several documents forming the contact are to be taken as mutually explanatory of one

another, detailed drawings being followed in preference to small scale drawing and figured

dimensions in preference to scale and special conditions in preference to General Conditions.

7.1 In case of any other discrepancies, not covered above, the Delhi Jal Board will resolve the same fairly

considering the nature of discrepancy. The decision of the Delhi Jal Board shall be final in this regard

and in case the same is not acceptable to the Bidder, his offer will not be considered.

7.2 If there are varying or conflicting provisions made in any one document forming part of thecontract, the Accepting Authority shall be the deciding authority with regard to the intention of the

document and his decision shall be final and binding on the contractor.

7.3 Any error in description, quantity or rate in Schedule of Quantities or any omission there from shall

not vitiate the contract or release the Contractor from the execution of the whole or any part of

the works comprised therein according to drawings and specifications or from any of this

obligations under the contract.

8. Signing of Contract

The successful tenderer/contractor, on acceptance of his tender by the Accepting Authority, shallwithin 15 days from the stipulated date of start of the work, sign the contract consisting of :-

i) The notice inviting tender, all the documents including drawings, if any, forming the tender asissued at the time of invitation of tender and acceptance thereof together with any correspondenceleading thereto.

ii) Standard D. J.B. Form as mentioned in Schedule "F" consisting of:a. Various standard clauses with corrections upto the date stipulated in Schedule "F" along with

annexure thereto.

b. D.J.B. Safety Code.c. Model Rules for the protection of health, sanitary arrangements for workers employed by D.J.B. or

its contractors.

d. D.J.B. Contractor's Labour Regulations.e. List of Acts and omissions for which fines can be imposed.

iii) No payment for the work done will be made unless contract is signed by the contractor.


7/30/2019 341_2013-03-29-13-44-18_1364544858

16/109

16

9. Objective

To deails mentioned in NIT.

10. Scope of Work

In this section broader details of works have been mentioned for the bidder to have an assessment about

the scope of work involved in this project but shall not be limited to this. The scope of work will include

all related works (civil), which will be required for successful completion and commissioning of the

proposed scheme. The interested bidder may like to refer Special Conditions of the work contained

herewith.

11. Alignment

The alignment for replacing the old PVC lines is depicted in enclosed Map.In case there is a change in

alignment due to reasons whatsoever, work has to be carried out on alternative alignment approved bythe Engineer-in-Charge and shall be binding on the contractor.

12. Excavation

The pipeline generally follows the road edge and excavation may involve cutting of bituminous road.

Some portion of the alignment follows Katcha path and in few sections pipe has to be laid along

parks/farming land.

The contractor shall take necessary permission from various authorities like PWD, DDA, Powerdistribution companies in the area viz. BSES Rajdhani, Horticulture department, MCD, MTNL. etc. to

facilitate laying of pipeline. The Delhi Jal Board shall however to assist the contractor in obtaining such

permissions by issuing recommendation letters.During excavation, strata of any type ranging from ordinary soil to rock may be met with, the provision

in BOQ is taken for all kinds of strata of soil/ rocks.

13.Execution of works

All the works shall be executed as per CPWD specifications including latest amendments and relevant

IS codes and Technical Specifications. As the work is of a prestigious/ urgent nature, the contractor hasto complete the job to the full satisfaction of the Engineer-in-charge and within stipulated schedule time

period as per Work order. The main components of works involved are:

Providing, laying and jointing Ductile Iron (C.I/D.I.) or MS pipes duly cement mortar lined frominside and fiber reinforced coal tar coating from outside

Control valves (sluice valves), scour valves and air valves provided at suitable points as per L-section which shall be prepared by the contractor during executing the work. L-section of the laidpipe line shall comprised ground levels, IL/Top of pipe. The contractor will submit 6 sets of final L-

section along with the final bill.

Thrust blocks, valve chamber and all related civil works required for successful completion of theproject.

14. Tendering procedure

The Tenderer shall be deemed to have read and examined the Tender Documents before quoting the

rates of all items in the Bill of Quantities and the schedule of Rates. The drawing(s),

Specifications, Clauses and Conditions, etc are to be considered as explanatory of each other and no

advantage shall be taken of any omission in Tender Documents.The tender procedure followed is of two-bid system where the bidder will submit bid under two bid

system i.e. Bid part-A (Technical) & Bid Part-B (Financial) through Online Submission of tender at website

as already mentioned Bill of quantities for two options has been provided with the bid document.

The bidder will be required to quote price for one option only as per his convenience. However DJB reserves the right to reject any tender with out assigning any reason whatsoever.


7/30/2019 341_2013-03-29-13-44-18_1364544858

17/109

17

Detailed instruction / information regarding the project have been further elaborated in the tender

documents under the sectional head Instruction to bidders, general conditions, conditions of contract,

special conditions, Technical specifications, etc.Quantities given in the annexed BOQs for the various items are approximate only. The basis for

payment will be the actual quantities of work done as measured. Variations in quantities of work in the

BOQs shall not vitiate the contract.

15 Forfeiture of Earnest Money

15.1 If any tenderer withdraws his tender before the expiry of validity period, or before the issue of letter of

acceptance, which ever is earlier, or makes any modification in terms and conditions of the tender which are not

acceptable to the department, than the department shall, without prejudice to any other right or remedy, be at

liberty to forfeit 100 % of the Earnest Money absolutely. This provision would naturally apply only to the lowest

tenderer once the earnest money of all the tenderer except those of the lowest is refunded.

15.2 If the contactor fails to furnish the prescribed Performance Guarantee within the prescribed period, the earnest

money is absolutely forfeited.

15.3 In case the contractor after issue of work order fails to commence the work specified in the tender documents on

the 15th

day or such time period as mentioned in letter of award, after the date on which the Engineer-in-chargeissues written orders to commence the work, or from the date of handing over of the site which ever is later, the

department shall, without prejudice to any other right or remedy, be at liberty to forfeit whole of the earnest

money absolutely.

15.4 In case of forfeiture of earnest money as prescribed above, the tenderer shall not be allowed to participate in the retendering process of the work.

16. 1 Site VisitThe Tenderer are expected to visit the site and examine the alignment to get themselves thoroughly

acquainted and to have their own independent observation, enquiries with the nature, position, extent

and practicality of the works, means of access, storage area for material and all other matters which can

in any way influence his tender price, as no monetary or other claims made by the tenderer on the

grounds of want of knowledge / information of any or all of the aforesaid matters will be entertained.

The Tenderer shall visit the site and make himself thoroughly familiar with the site conditions,accessibility, all other possible difficulties and other requirements mentioned elsewhere in his Tender

prior to submission. When a Tenderer submits his tender for this work, it will be considered that hehas quoted for this work with full and complete knowledge of the site and prevailing conditions, and

no claim for additional compensation shall be entertained on this account. The Tenderer shall be

deemed to be fully conversant with other extensive development and construction work currently

being in progress or may start in future on and around the site and all changes in the nature andcondition of the site from that existing at the time of Tender. The cost of visiting the site shall be at the

bidders expense.

The contractor shall be deemed to have inspected and examined the site to know the nature of soil &

sub-soil water table. The contractor shall provide everything for successful completion of the work likelabour, material, equipment and other accessories required, as per drawings, specifications and as

directed by Engineer-in-Charge.

In case any clarification or information is needed for site of work, the intending tenderer may contact

office of the Executive Engineer (WEST) III

17. Rates

In present case of percentage rate tender only percentage above or below on the bill of quantity shall beconsidered. Percentage quoted by the tenderer shall be accurately filled in figures and words, and if there

is any discrepancy between amounts filled in figures and words then the amount filled in figures will be

assumed correct and final.

As in present case, the bill of quantities each with different class of material is provided with the tender

documents, the bidder shall have option to offer the rate for any one of the bill of quantities. However,


7/30/2019 341_2013-03-29-13-44-18_1364544858

18/109

18

it may be noted that the lowest total cost of the work, worked out on either of the bill of quantity shall be

taken into consideration for evaluating the lowest offer.

The Description of the Item given in BOQs are mostly based on DSR-2012. However, someadditional items are also given. In respect of Items & rates of BOQs, which are as per DSR-2012, if

there is any discrepancy between the tender BOQs and those given in the DSR-2012, then the

description of item and its corresponding rate given in the DSR-2012 shall prevail.

Extra items of work shall not vitiate the contract. The Tenderer shall be bound to execute extra items of

work as directed by the Engineer-in-charge. The rates for extra items will be as per rates decided under

Contract Conditions.

17.1The tendered rate (%age rate tender/item rate tender) for all items of the work shall be considered inclusiveof all leads and lifts, skilled or unskilled labour & material required for working at all heights and depths, making any

shape of the masonry as per the drawings, royalty fee, terminal taxes, octroi, entry tax etc. besides other taxes payable

by the contractor such as Income Tax and Sales Tax on work contract and the sales tax applicable on the goods/

material. Nothing extra shall be paid unless otherwise given in the description of item and not extra claim shall be

entertained due to any reasons whatsoever on this account.

17.2Nothing extra shall be paid unless otherwise specified on account of cutting of grass, bushes, leveling of undulationin the ground, existence of drain and temporary structures etc. requiring removal and difficulty due to space

constraints. For pipeline works nothing extra shall be paid on account of interconnection of water lines with existing

one or new one.

17.3Nothing extra shall be paid for working in foul conditions unless otherwise specified. The tendered rates shall not besubject to any revisions for want of any information.

17.4a) Rates quoted by the contractor shall be inclusive of the exemption extended by the Central Govt. to theexcisable goods of the description specified in the General Exemption No .49 of the finance Act.2010.b) In this context, the DJB will issue recommendatory letter, as per the government guidelines for issuance of

essential certificate from the Collector/ Deputy Commissioner of the District, so as to enable the Contractor to get

the benefit against Zero excise duty. The recommendatory letter shall be given only for those items which are

within the preview of exemption and are consumed during the execution of the work.

c) All exercise required for receiving the benefit of exemption under the contract shall be done by the contractorsolely and DJB will not provide any assistance in this regard other than issuing recommendatory letter. Further,

DJB shall not be liable, in any manner whatsoever, for rejection of contractors claim, for any reason whatsoever.

d) Notwithstanding what is stated above, the contractor should also consider the position with regard to the goods

against Zero Excise Duty. DJB will not bear any responsibility for incorrect assessment, if any of the statutory

levies by the contractor. As the above statutory provisions are liable for review by the government of India, the

contractors are advised to check the latest position in their own interest.

e) Any statutory variations both plus and minus in the rate of excise duty within the contractualcompletion periodwill be to the account of DJB. Any increase in Excise Duty during the period between the stipulated date of

completion and actual date of completion in case of late completion will be to bidders account. This is without

prejudice to any other clause including liquidated Damages clause.

17.1 Service tax shall not be added in the quoted rates. Service tax shall be reimbursed to the contractor as peractual subject to submission of necessary documentary proof etc as desired by engineer in charge. If any penalty

imposed by the service tax department on the intending bidder for the delayed submission of service tax then

penalty amount shall not be considered by the department in any case.

17.2 Part B: Price BidIt shall consist of percentage rate above/below as per BOQ. Financial bids of only those bidders would be openedwhose bid is strictly as per NIT/Addendum issued by department.

18. 1. Documents

Bidders shall carefully examine the Tender Specification and fully inform themselves as to all the conditions and

matters, which may in any way affect the work or the cost thereof. Should a Bidder find discrepancies in or

omissions from the Tender Specification or should he be in doubt as to their meaning, he should at once address a

query to the DJB with a copy to the concerned SE three days before scheduled date of submission of bids. Anyresulting interpretation or modifications of the Tender Specification shall be issued as an Addendum.


7/30/2019 341_2013-03-29-13-44-18_1364544858

19/109

19

18.2. Validity of tendered rates

The quoted rates shall hold good for 120 days from the date of receipt of the tenders . In exceptional

circumstances, prior to the expiry of the original time limit the DJB may request the bidder to extend the period

of validity for a specified additional period. However the bidder agreeing to the request will not be permitted to

modify the rates/price of his/their bid and the extension of validity of rates shall be on the same terms and

conditions as contained in the tender documents.

18.3 Rejection of tendersThe DJB is not bound to accept the lowest or any other tender, and reserves the right to reject any or all the

tenders without assigning any reason.

19. Cost of Tendering

The DJB will not be responsible for any expenses incurred by the Bidder in tendering, preparation of tender, in

providing clarification, attending meetings conferences etc.

20. Division of workThe Engineer-in-Charge reserves the right to divide or reduce the work and the tenderer will be bound to execute

the portion of work, allotted to him. The contractor shall carry out the work in part, at the site as made availableand no claim on this account shall be entertained. The time period for completion will also be amended on prorata

basis keeping in view the nature of work allotted, if the scope of work is reduced or divided.

21. Time of Completion

The entire work in the scope of the Contractor is required to be completed within (details mentioned in NIT

Formate)from the date of start mentioned in Letter of Intent or Work Order, whichever is earlier. The work shall

generally proceed in accordance with the agreed bar chart/ CPM/work program.

22. Contract agreement

After the acceptance of the tender, the tenderer will have to submit necessary papers for execution of contract

agreement and sign the same within the time frame mentioned in the work order. In case of delay by thecontractor, the Engineer-in-Charge reserves the right to cancel the award of work and forfeit the Earnest Money

without any legal notice.

23. Eligibility Criteria

23.1 The tenderer should fulfill the eligibility criteria as detailed in NIT and include in their Technical proposal all the

relevant documents required in support of their eligibility in applying for this tender.

23.2 While evaluating the Technical bids, if no reply is received in respect of any bidder regarding verification of

documents submitted by the bidder e.g. work experience certificates, credentials of the firm, solvency, financial

capabilities, bank guarantee etc. from the concerned issuing agencies, till the opening of price/ financial bid, the

same will not be opened and considered for the award of work.

EX. ENGINEER (WEST) III


7/30/2019 341_2013-03-29-13-44-18_1364544858

20/109

20

CLAUSES OF CONTRACT

CLAUSE 1 Performance Guarantee.(i) The contractor shall submit an irrevocable PERFORMANCE GUARANTEE of 5%(five percent) of the

tendered amount in addition to other deposits mentioned elsewhere in the contract for his proper

performance of the contract agreement, (not withstanding and / or without prejudice to any other

provisions in the contract) within 10 DAYS of issue of letter of acceptance. This period can be further

extended by the engineer-in-charge up to a maximum period of3 days on written request of the contractor

stating the reason for delays in procuring the Performance Guarantee to the satisfaction of the engineer in

charge. This guarantee shall be in the form of Cash (in case guarantee amount is less than Rs. 10,000.00)or Deposit at Call receipt of any schedule Bank / Bankers cheque of any scheduled Bank / Demand Draft

of any scheduled Bank / Pay Order of any scheduled Bank (in case guarantee amount is less than Rs. 1,00,000.00) or Government Securities or Fixed Deposit Receipts or Guarantee Bonds of any Scheduled

Bank or the State Bank of India in accordance with the form annexed hereto. In case a fixed deposit receiptof any bank is furnished by the contractor to Delhi Jal Board as part of the Performance Guarantee and the

bank is unable to make payment against the said fixed deposit receipt, the loss caused thereby shall fall on

the contractor and the contractor shall forthwith on demand furnish additional security to Delhi Jal Board

to make good the deficit.

(ii) The performance guarantee shall be initially valid up to the stipulated date of completion plus 60 days

beyond that. In case the time for completion of work gets enlarged, the contractor shall get the validity ofPerformance guarantee extended to cover such enlarged time for completion of work. After recording of

the completion certificate for the work by the competent authority, the performance guarantee shall be

returned to the contactor, without any interest.

(iii) The Engineer-In-Charge shall not make a claim under the performance guarantee except for amounts towhich DELHI JAL BOARD is entitled under the contract (notwithstanding and / or without prejudice to

any other provisions in the contract agreement) in the event of:

a. Failure by the contractor to extend the validity of the performance guarantee as described herein above, inwhich event the engineer-in-charge may claim the full amount of the performance guarantee.

b. Failure by the contractor to pay Delhi Jal Board any amount due, either as agreed by the contractor ordetermined under any of the Clauses / Conditions of the agreement, within 30 days of the service of notice

to this effect by Engineer-in-Charge.

(iv) In the event of the contract being determined or rescinded under provision of any of the clause / condition

of the agreement, the performance guarantee shall stand forfeited in full and shall be absolutely at the

disposal of the Delhi Jal Board.

CLAUSE 1A Recovery of Security Deposit

The person/persons whose tender(s) may be accepted (hereinafter called the contractor) shall permit Gov-

ernment at the time of making any payment to him for work done under the contract to deduct a sum at

the rate of 5% of the gross amount of each running bill till the sum along with the sum already deposited

as earnest money, will amount to security deposit of 5% of the tendered value of the work. Suchdeductions will be made and held by Government by way of Security Deposit unless he/they has/have

deposited the amount of Security at the rate mentioned above in cash.

All compensations or the other sums of money payable by the contractor under the terms of this contract may be

deducted from, or paid by the sale of a sufficient part of his security deposit or from the interest arisingthereon, or from any sums which may be due to or may become due to the contractor by Government on

any account whatsoever and in the event of his Security Deposit being reduced by reason of any such


7/30/2019 341_2013-03-29-13-44-18_1364544858

21/109

21

deductions or sale as aforesaid, the contractor shall within 10 days make good in cash deducted from, or

raised by sale of his security deposit or any part thereof. The security deposit shall be collected from the

running bills of the contractor at the rates mentioned above and the Earnest Money if deposited in cashat the time of tenders will be treated a part of the Security Deposit.

Clause 2 Compensation for Delay

If the contractor fails to maintain the required progress in terms of clause 5 or to complete the work and clear

the site on or before the contract or extended date of completion, he shall, without prejudice, to any

other right or remedy available under the law to the Government on account of such breach, pay as

agreed compensation the amount calculated at the rates stipulated below as the Superintending

Engineer (whose decision in writing shall be final and binding) may decide on the amount of tendered

valve of the work for every completed day/month (as applicable) that the progress remains below that

specified in Clause 5 or that the work remains incomplete.

This will also apply to items or group of items for which a separate period of completion has been

specified.

Compensation for delay of work @ 1.5% per month delay to be

computed on per day basis

Provided always that the total amount of compensation for delay to be paid under this condition shall not

exceed 10% of the Tendered Value of work or to the Tendered Value of the item or group of items ofwork for which a separate period of completion is originally given.

The amount of compensation may be adjusted or set-off against any sum payable to the Contractor under this or

any other contract with the Government. In case, the contractor does not achieve a particular milestone

mentioned in schedule-F, or the rescheduled milestone(s) in terms of Clause 5.4, the amount shown

against that milestone shall be withheld, to be adjusted against the compensation levied at the final grantof extension of time. Withholding of this amount on failure to achieve milestones shall be automatic

without any notice to the contractor. However, if the contractor catches up with the progress of work on

the subsequent milestone(s), the withheld amount shall be released. In case the contractor fails to makeup for the delay in subsequent milestone(s), amount mentioned against each milestone missed

subsequently also shall be withheld. However, no interest, whatsoever, shall be payable on such

withheld amount.

Clause 2 A Incentive for early completion

In case, the contractor completes the work ahead of scheduled completion time, a bonus @ 1% (One

per cent) of the tendered value per month computed on per day basis, shall be payable to the

contractor, subject to a maximum limit of 5% (five percent) of the tendered value. The amount of

bonus, if payable shall be paid along with final bill after completion of work. Provided always that

provision of the Clause 2 A shall be applicable only when so provided in Schedule F.

CLAUSE 3 When Contract Can Be Determined

Subject to other provisions contained in this clause, the Engineer-in-Charge may, without prejudice to his

any other rights or remedy against the contractor in respect of any delay, inferior workmanship, any claims

for damages and / or any other provisions of this contract or otherwise, and whether the date of completion

has or has not elapsed, by notice in writing absolutely determine the contract in any of the following cases:

i) If the contractor having been given by the Engineer-in-Charge a notice in writing to rectify, reconstruct or

replace any defective work or that the work is being performed in an inefficient or otherwise improper un-workman like manner shall omit to comply with the requirement of such notice for a period of seven days

thereafter.


7/30/2019 341_2013-03-29-13-44-18_1364544858

22/109

22

(ii) If the contractor has, without reasonable cause, suspended the progress of the work or has failed to proceed

with the work with due diligence so that in the opinion of the Engineer-in-Charge (which shall be final and

binding) he will be unable to secure completion of the work by the date for completion and continues to doso after a notice in writing of seven days from the Engineer-in- Charge.

iii) If the contractor fails to complete the work within the stipulated date or items of work with individual date

of completion, if any stipulated, on or before such date(s) of completion and does not complete them withinthe period specified in a notice given in writing in that behalf by the Engineer-in-Charge.

iv) If the contractor persistently neglects to carry out his obligations under the contract and / or commits default

in complying with any of the terms and conditions of the contract and does not remedy it or take effective

steps to remedy it within 7 days after a notice in writing is given to him in that behalf by the Engineer-in-

Charge.

v) If the contractor shall offer or give or agree to give to any person in Government service or to anyother person on his behalf any gift or consideration of any kind as an inducement or reward for

doing or forbearing to do or for having done or forborne to do any act in relation to the obtainingor execution of this or any other contract for Government.

vi) If the contractor shall enter into a contract with Government in connection with which commission

has been paid or agreed to be paid by him or to his knowledge, unless the particulars of any such

commission and the terms of payment thereof have been previously disclosed in writing to the

Engineer in charge.

vii)If the contractor shall obtain a contract with government as a result of wrong tendering or othernon-bonafide methods of competitive tendering.

viii) If the contractor being an individual, or if a firm, any partner thereof shall at any time beadjudged insolvent or have a receiving order or order for administration of his estate made against

him or shall take any proceedings for liquidation or composition (other than a voluntary liquidation for

the purpose of amalgamation or reconstruction) under any Insolvency Act for the time being in forceor make any conveyance or assignment of his effects or composition or arrangement for the benefit

of his creditors or purport so to do, or if any application be made under any insolvency Act for the

time being in force for the sequestration of his estate or if a trust deed be executed by him for

benefit of his creditors.

ix) If the contractor being a company shall pass a resolution or the court shall made an order that thecompany shall be wound up or if a receiver or a manager on behalf of a creditor shall be appointed

or if circumstances shall arise which entitle the court or the creditor to appoint a receiver or a

manager or which entitle the court to make a winding up order.

x) If the contractor shall suffer an execution being levied on his goods and allow it to be continuedfor a period of 21 days.

xi) If the contractor assigns, transfers, sublets (engagement of labour on a piece work basis or of labour

with materials not to be incorporated in the work, shall not be deemed to be subletting) or otherwise

parts with or attempts to assign, transfer, sublet or otherwise parts with the entire works or any portion

thereof without the prior written approval of the Engineer-in-charge.

xii) If the work is not started by the contractor within 1/8th of the stipulated time.When the contractor has made himself liable for action under any of the cases aforesaid, the

Engineer-in-Charge on behalf of the Delhi Jal Board shall have powers:

a) To determine the contract as aforesaid (of which termination notice in writing to the contractor under the

hand of the Engineer-In-Charge shall be conclusive evidence). Upon such determination, the Earnest

Money Deposit, Security Deposit already recovered and performance guarantee under the contract shall beliable to be forfeited and shall be absolutely at the disposal of the Government


7/30/2019 341_2013-03-29-13-44-18_1364544858

23/109

23

b) After giving notice to the contractor to measure up the work of the contractor and to take such whole, or the

balance or part thereof, as shall be un-executed out of his hands and to give it to another contractor to

complete the work. The contractor, whose contract is determined as above, shall not be allowed toparticipate in the tendering process for the balance work.

In the event of above courses being adopted by the Engineer-in-Charge, the contractor shall have no claim

to compensation for any loss sustained by him by reasons of his having purchased or procured any materials

or entered into any engagements or made any advance on account or with a view to the execution of the

work or the performance of the contract. And in case action is taken under any of the provision aforesaid,

the contractor shall not be entitled to recover or be paid any sum for any work thereof or actually performed

under this contract unless and until the Engineer-in-Charge has certified in writing the performance of

such work and the value payable in respect thereof and he shall only be entitled to be paid the value so

certified.

Clause 3A

In case, the work cannot be started due to reasons not within the control of the contractor within1/8th of the stipulated time for completion of work, either party may close the contract. In such

eventually, the Earnest money deposit and the performance Guarantee of the contractor shall be

refunded, but no payment on account of interest, loss of profit or damages etc. shall be payable at

all.

CLAUSE 4 Contractor liable to pay Compensation even if action not taken under Clause 3

In any case in which any of the powers conferred upon the Engineer-in charge by clause 3 thereof, shall

have become exercisable and the same are not exercised, the non exercise thereof shall not constitute a

waiver of any of the conditions hereof and such powers shall notwithstanding be exercisable in the event of

any future case of default by the contractor and the liability of the contractor for compensation shall remain

unaffected. In the event of the Engineer-in-Charge putting in force all or any of the powers vested in himunder the preceding clause he may, if he so desires after giving a notice in writing to the contractor, take

possession of (or at the sole discretion of the Engineer-in-Charge which shall be final and binding on the

contractor) use as on hire (the amount of the hire money being also in the final determination of the

Engineer-in-Charge) all or any tools, plant, materials and stores, in or upon the works, or the site thereofbelonging to the contractor, or procured by the contractor and intended to be used for the execution of the

work / or any part thereof, paying or allowing for the same in account at the contract rates, or, in the case of

these not being applicable, at current market rates to be certified by the Engineer-in-Charge, whose

certificate thereof shall be final, and binding on the contractor, clerk of the works, foreman or otherauthorized agent to remove such tools, plant, material, or stores from the premises (within a time to be

specified in such notice) in the event of the contractor failing to comply with any such requisition, the

Engineer-in-Charge may remove them at the contractors expense or sell them by auction or private sale

on account of the contractor and his risk in all respects and the certificate of the Engineer-in-Charge asto the expenses of any such removal and the amount of the proceeds and expenses of any such sale shall be

final and conclusive against the contractor.

CLAUSE 5 Time and Extensions for Delay

The time allowed for execution of the works as specified in the Schedule F or the extended time in

accordance with these conditions shall be the essence of the Contract. The execution of the works shall com-

mence from the 15th Day or such time period as mentioned in letter of Award. If the Contractor commitsdefault in commencing the execution of the work as aforesaid, Government shall without prejudice to any

other right or remedy available in law, be at liberty to forfeit the earnest money & performance guarantee

absolutely.

5.1 As soon as possible after the contract is concluded the Contractor shall submit a Time & Progress Chart

for each milestone and get it approved by the Department. The Chart shall be prepared in direct relation to


7/30/2019 341_2013-03-29-13-44-18_1364544858

24/109

24

the time stated in the Contract documents for completion of items of the works. It shall indicate the forecast

of the dates of commencement and completion of various trades of sections of the work and may be

amended as necessary by agreement between the Engineer-in-Charge and the Contractor within thelimitations of time Imposed in the contract documents, and further to ensure good progress during the

execution of the work, the contractor shall in all cases in which the time allowed for any work, exceeds one

month (save for special jobs for any work a separate program has been agreed upon) complete the work asper milestone given in schedule "F".

5.2If the work(s) be delayed by:

a. Force majeure, or

b. Abnormally bad weather orc. Serious loss or damage by fire ord. Civil commotion local commotion of workmen, strike or lockout, affecting any of the trades employedon the work, or

e. Delay on the part of other contractors or tradesmen engaged by Engineer-in-Charge executing work notforming part of the Contract, or

f. Non-availability of stores, which are the responsibility of Government to supply org. Non-availability or break down of tools and Plant to be supplied or supplied Government. Orh. Any other cause which, in the absolute discretion of the authority mentioned Schedule F is beyondthe Contractors control.

Then upon the happening of any such event causing delay, the Contractor shall immediately give notice

thereof in writing to the authority as indicated in Schedule F but shall nevertheless use constantly his best

endeavors to prevent or make good the delay and shall do an that may be reason required to the satisfaction

of the Engineer-in-Charge to proceed with the works.

5.3 Request for rescheduling of Milestones and extension of time, to be eligible for consideration, shall be

made by the Contractor in writing within fourteen days of the happening of the event causing delay on theprescribed form to the authority as indicated in Schedule F. The Contractor may also, if practicable, indicate

in such a request the period for which extension is desired.

5.4 In any such case the authority as indicated in Schedule F may give a fair and reasonable extension of

time and reschedule the milestones for completion of work. Such extension shall be communicated to thecontractor by the authority as indicated in Schedule F in writing, within 3 months of the date of receipt ofsuch request. Non application by the contractor for extension of time shall not be a bar for giving a fair and

reasonable extension by the authority as indicated in Schedule F and this shall be binding on the contractor.

CLAUSE 6 MEASUREMENTS OF WORK DONE

Engineer-in-Charge shall, except as otherwise provided, ascertain and determine by measurement the

value in accordance with the contract of work done.

All measurement of all items having financial value shall be entered in Measurement Book and / or level

field book so that a complete record is obtained of all works performed under the contract.

All measurements and levels shall be taken jointly by the Engineer-in-Charge or his authorized

representative and by the contractor or his authorized representative from time to time during the progress of

the work and such measurements shall be signed and dated by the Engineer-in-Charge and the contractor

or their representatives in token of their acceptance. If the contractor objects to any of the measurements

recorded, a note shall be made to that effect with reason and signed by both the parties.


7/30/2019 341_2013-03-29-13-44-18_1364544858

25/109

25

If for any reason the contractor or his authorized representative is not available and the work of recording

measurements is suspended by the Engineer-in-Charge or his representative, the Engineer-in-Charge and

the Department shall not entertain any claim from contractor for any loss or damages on this account. If thecontractor or his authorized representative does not remain present at the time of such measurements after

the contractor or his authorized representative has been given a notice in writing three (3) days in advance or

fails to countersign or to record objection within a week from the date of the measurement, then suchmeasurements recorded in his absence by the Engineer-in-Charge or his representative shall be deemed to

be accepted by the Contractor.

The contractor shall, without extra charge, provide all assistance with every appliance, labour and otherthings necessary for measurements and recording levels.

Except where any general or detailed description of the work expressly shows to the contrary, measurements

shall be taken in accordance with the procedure set forth in the specifications notwithstanding any provision

in the relevant Standard Method of measurement or any general or local custom. In the case of items whichare not covered by specifications, measurements shall be taken in accordance with the relevant standard

method of measurement issued by the Bureau of Indian Standards and if for any item no such standard is

available, then a mutually agreed method shall be followed.The contractor shall give, not less than seven days notice to the Engineer-in-Charge or his authorized

representative in charge of the work, before covering up or otherwise placing beyond the reach ofmeasurement any work in order that the same may be measured and correct dimensions thereof be taken

before the same is covered up or placed beyond the reach of measurement and shall not cover up and place

beyond reach of measurement any work without consent in writing of the Engineer-in-Charge or his

authorized representative in charge of the work who shall within the aforesaid period of seven days inspect

the work, and if any work shall be covered up or placed beyond the reach of measurements without such

notice having been given or the Engineer-in-Charges consent being obtained in writing, the same shall be

uncovered at the Contractors expense, or in default thereof no payment or allowance shall be made for such

work or the materials with which the same was executed.

Engineer-in-Charge or his authorized representative may cause either themselves or through another officer

of the department to check the measurements recorded jointly or otherwise as aforesaid and all provisions

stipulated herein above shall be applicable to such checking of measurements or levels.

It is also a term of this contract that recording of measurements of any item of work in the measurement

book and / or its payment in the interim, on account or final bill shall not be considered as conclusive

evidence as to the sufficiency of any work or material to with it relates nor shall it relieve the contractor

from liabilities from any over measurement or defects noticed till completion of the defects liability period.

Clause 6A Computerized Measurement Book

Engineer-in-Charge shall, except as otherwise provided, ascertain and determine by measurement the

value of work done in accordance with the contract.All measurements of all items having financial value shall be entered by the contractor and

compiled in the shape of the computerized Measurement Book having pages of A-4 size as per the

format of the department so that a complete record is obtained of all the items of works performed

under the contract.

All such measurements and levels recorded by the contractor or his authorized representative from

time to time, during the progress of the work, shall be got checked by the contractor from the

Engineer-in-Charge or his authorized representative as per interval or program fixed in consultation

with Engineer-in-Charge or his authorized representative as per interval or program fixed inconsultation with Engineer-in-Charge or his authorized representative. After the necessary corrections

made by the Engineer-in-Charge, the measurement sheets shall be returned to the contractor for

incorporating the corrections and for resubmission to the Engineer-in-Charge for the dated


7/30/2019 341_2013-03-29-13-44-18_1364544858

26/109

26

signatures by the Engineer-in-charge and the contractor or their representatives in token of their

acceptance.

Whenever bill is due for payment, the contractor would initially submit draft computerized

measurement sheets and these measurements would be got checked / test checked from the Engineer-

In-Charge and / or his authorized representative. The contractor will, thereafter, incorporate such

changes as may be done during these checks / test checks in his draft computerized measurements,and submit to the department a computerized measurement book, duly bound, and with its pagesmachine numbered. The Engineer-in-charge and / or his authorized representative would thereafter

check this MB, and record the necessary certificates for their checks / tests checks.

The final, fair, computerized measurement book given by the contractor, duly bound, with its pages

machine numbered, should be 100% correct, and no cutting or over-writing in the measurements would

thereafter be allowed. If at all any error is noticed, the contractor shall have to submit a fresh computerized

MB with its pages duly machined numbered and bound after getting the earlier MB cancelled by thedepartment. Thereafter, the MB shall be taken in the Divisional Office records, and allotted a number as per

the Register of Computerized MBs. This should be done before the corresponding bill is submitted to the

Division Office for payment. The contractor shall submit two spare copies of such computerized MBs forthe purpose of reference and record by the various officers of the department.

The contractor shall also submit to the department separately his computerized Abstract of Cost and the billbased on these measurements, duly bound, and its pages machine numbered along with two spare copies of

the bill. Thereafter, this bill will be processed by the Division Office and allotted a number as per the

computerized record in the same way as done for the measurement book meant for measurements.

The contractor shall, without extra charge, provide all assistance with every appliance, labour and other

things necessary for checking of measurements / levels by the Engineer-in-Charge or his representative.

Except where any general or detailed description of the work expressly shows to the contrary,

measurements shall be taken in accordance with the procedure set forth in the specifications notwithstanding

any provision in the relevant Standard Method of measurement or any general or local custom. In the caseof items which are not covered by Specifications, measurements shall be taken in accordance with the

relevant standard method of measurement issued by the Bureau of Indian Standards and if for any item nosuch standard is available then a mutually agreed method shall be followed.

The contractor shall give not less than seven days notice to the Engineer-in-Charge or his authorized

representative in charge of the work before covering up or otherwise placing beyond the reach of checking

and / or test checking the measurement of any work in order that the same may be checked and / or test

checked and correct dimensions thereof be taken before the same is covered up or placed beyond the reachof checking and /or test checking measurement and shall not cover up and place beyond reach of

measurement any work without consent in writing of the Engineer-in-Charge or his authorized

representative in charge of the work who shall within the aforesaid period of seven days inspect the work,

and if any work shall be covered up or placed beyond the reach of checking and / or test checkingmeasurements without such notice having been given or the Engineer-in-Charges consent being obtained

in writing the same shall be uncovered at the Contractors expense, or in default thereof no payment or

allowance shall be made for such work or the materials with which the same was executed.

Engineer-in-Charge or his authorized representative may cause either themselves or through another

officer of the department to check the measurements recorded by contractor and all provisions stipulated

herein above shall be applicable to such checking of measurements of levels.

It is also a term of this contract that checking and / or test checking the measurements of any item of work in

the measurement book and / or its payment in the interim, on account of final bill shall not be considered as

conclusive evidence as to the sufficiency of any work or material to which it relates nor shall it relieve the

contractor from liabilities from any over measurement or defects noticed till completion of the defectsliability period.


7/30/2019 341_2013-03-29-13-44-18_1364544858

27/109

27

CLAUSE 7 - Payment on Intermediate Certificate to Be Regarded As Advances

No payment shall be made for work, estimated to cost Rs. Twenty thousand or less till after the whole of the

work shall have been completed and certificate of completion given. For works estimated to cost over Rs.

Twenty thousand, the interim or running account bill shall be submitted by the contractor for the work

executed on the basis of such recorded measurements on the format of the Department in triplicate on or

before the date of every month fixed for the same by the Engineer-in-Charge. The contractor shall not beentitle to be paid any such interim payment if the gross work done together with net payment / adjustment ofadvances for material collected, if any, since the last such payment is less than the amount specified in

Schedule F, in which case the interim bill shall be prepare on the appointed date of the month after therequisite progress is achieved. Engineer-in Charge shall arrange to have the bill verified by taking or

causing to be taken, where necessary, the requisite measurements of the work.. In the event of the failure of

the contractor to submit the bills, Engineer-in-Charge shall prepare or cause to be prepare such bills in

which event no claims whatsoever due to delays on payment including that of interest shall be payable to the

contractor. Payment on account of amount admissible shall be made by the Engineer-in-Charge certifying

the sum to which the contractor is considered entitled by way of interim payment at such rates as decided by

the Engineer-in-Charge. The amount admissible shall be paid by 10th working day after the day of

presentation of the bill by the Contractor to the Engineer-in-Charge or his Asstt. Engineer together withthe account of the material issued by the department, or dismantled materials, if any. In the case of works

outside the headquarters of the Engineer-in-Charge the period of ten working days will be extended to

fifteen working days.

All such interim payments shall be regarded as payment by way of advances against final payment only andshall not preclude the requiring of bad, unsound and imperfect or unskilled work to be rejected, removed,

taken away and reconstructed or re-erected. Any certificate given by the Engineer-in-Charge relating to the

work done or materials delivered forming part of such payment, may be modified or corrected by any

subsequent such certificate(s) or by the final certificate and shall not by itself be conclusive evidence that

any work or materials to which it relates is / are in accordance with the contract and specifications. Any

such interim payment, or any part thereof shall not in any respect conclude, determine or affect in any waypowers of the Engineer-in-Charge under the contract or any of such payments be treated as final settlement

and adjustment of accounts or in any way vary or affect the contract.

Pending consideration of extension of date of completion, interim payments shall continue to be made as

herein provided without prejudice to the right of the department to take action under the terms of this

contract for delay in the completion of work, if the extension of date of completion is not granted by the

competent authority.

The Engineer-in-Charge in his sole discretion on the basis of a certificate from the Asstt. Engineer to the

effect that the work has been completed up to the level in question make interim advance payments without

detailed measurements for work done (other than foundations, items to be covered under finishing items) up

to lintel level (including sunshade etc.) and slab level, for each floor working out at 75% of the assessed

value. The advance payments so allowed shall be adjusted in the subsequent interim bill by taking detailed

measurements thereof.

Payments in Composite Contracts:

In case of composite tenders, running payment for the major component shall be made by EE of majordiscipline to the main contractor. Running payment for minor components shall be made by the Engineer-in-

charge of the discipline of minor component directly to the main contractor.

In case main contractor fails to make the payment to the contractor associated by him with in 15 days of

receipt of each running account payment, then on the written complaint of contractor associated for such